Vermont Prompt Payment Guide and FAQs

Ready? Build Your Free Vermont
Prompt Payment Now

Make Your Prompt Payment Demand Now
Vermont-Prompt-Payment-FAQ

Vermont Prompt Payment Overview

Vermont Prompt Payment Requirements


20
DAYS
Prime Contractors

For Prime Contractors, progress payment must be made within 20 days after the end of the billing period or 20 days after delivery of invoice.


7
DAYS
Subcontractors

For Subcontractors, payment due by the later of 7 days after payment is received from above, or 7 days after receipt of invoice.


7
DAYS
Suppliers

For Suppliers, payment due by the later of 7 days after payment is received from above, or 7 days after receipt of invoice.


12%
/ YEAR
Interest & Fees

Interest at 12% year. Attorneys' fees to prevailing party. Penalty of 1% month for amounts that were withheld "wrongly"

20
DAYS
Prime Contractors

For Prime (General) Contractors, payment due within the later of 20 days after the end of the billing period or 20 days after delivery of invoice.


7
DAYS
Subcontractors

For Subcontractors, payment due by the later of 7 days after payment is received from above, or 7 days after receipt of invoice.


7
DAYS
Suppliers

For Suppliers, payment due by the later of 7 days after payment is received from above, or 7 days after receipt of invoice.


12%
/ YEAR
Interest & Fees

Interest at 12% year. Attorneys' fees to prevailing party. Penalty of 1% month for amounts that were withheld "wrongly"

Prompt payment laws are a set of rules that regulate the acceptable amount of time in which payments must be made to contractors and subs. This is to ensure that everyone on a construction project is paid in a timely fashion. These statutes provide a framework for the timing of payments to ensure cash flow and working capital.

Projects Covered by Prompt Payment in Vermont

The Vermont prompt payment laws set payment deadlines and penalties for both public and private construction projects within the state. Both types of projects are regulated by the same laws found in Vt. Stat., Title 9, §§ 4001-4009.

Deadlines for Payment

Payments made from the public entity to the prime contractor will be determined by the contract terms. However, if the contract is silent, then the prompt pay deadlines are enforced. For all payments from the owner or public entity to the prime contractor, they must be released within 20 days of either the end of the billing period, or delivery of a request for payment; whichever is later. As for payments from the prime to subcontractors, these must be made within 7 days of either the prime receiving payment, or the prime’s receipt of the sub’s request for payment; whichever is later. The same deadline applies to all other payments down the payment chain.

Penalties for Late Payment

Vermont’s prompt payment laws do provide a list of reasons why payment can be properly withheld. If none of these circumstances exist, and payment is either late or wrongfully withheld, interest will begin accruing at a rate of 12% per year (1%/month). If the dispute goes to court, the prevailing party will be awarded attorney fees. If it is determined that the amounts were “wrongfully withheld” and additional 1% interest per month may be imposed.

Vermont Prompt Payment Frequently Asked Questions

Vermont Prompt Payment Private Projects FAQs

Do I have to send a letter or file anything to qualify for Prompt Payment Penalties or Remedies in Vermont?

In order for the provisions of the Vermont prompt pay statutes to apply, the party requesting payment must be entitled to payment pursuant to the terms of the contract, and must submit an invoice. In order for attorneys’ fees to be awarded, a claimant must be the prevailing party in an action to recover payments under the Act.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Can I include Prompt Payment Fees in my Vermont Mechanics Liens Claim or Bond Claim?

No. Vermont doesn’t allow miscellaneous amounts to be included on the face of a mechanics lien.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

If I am paid late according to Prompt Payment Statutes, can I obtain interest or other Penalty Payments?

Yes. Interest accrues at a rate of 12% per year, beginning the first day payment is late according to the prompt payment statutes.

A party that knowingly and wrongfully withholds payment is subject to an additional 1% per month penalty on the amount due. Amounts are not considered wrongfully withheld to the extent that the amount was reasonably related to an amount disputed in good faith.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Are there reasons for which payment may be withheld past the general deadline?

Vermont allows payments to be withheld for any good faith claim against the party requesting payment, including:

  1. Unsatisfactory job progress;
  2. Defective construction;
  3. Disputed work;
  4. Third party claims

Note, however that in the event payments are withheld pursuant to reason 2, above, the deficiency must be described in writing and delivered to the party requesting payment.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

What is the best practice for making a demand to a non-paying party to get Prompt Payment Fees?

Sending a notice of intent to lien and prompt payment demand is generally the best method for encouraging parties to make payment.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Vermont Prompt Payment Public Projects FAQs

Do I have to send a letter or file anything to qualify for Prompt Payment Penalties or Remedies in Vermont?

In order for the provisions of the Vermont prompt pay statutes to apply, the party requesting payment must be entitled to payment pursuant to the terms of the contract, and must submit an invoice. In order for attorneys’ fees to be awarded, a claimant must be the prevailing party in an action to recover payments under the Act.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Can I include Prompt Payment Fees in my Vermont Mechanics Liens Claim or Bond Claim?

No. Vermont doesn’t allow miscellaneous amounts to be included on the face of a bond claim.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

If I am paid late according to Prompt Payment Statutes, can I obtain interest or other Penalty Payments?

There is no specific prerequisite for interest to accrue on late payments in Vermont other than the requirement that the payment must be late pursuant to the prompt pay statute.

Further, note that a party that knowingly and wrongfully withholds payment is also subject to an additional 1% per month penalty on the amount due. Amounts are not considered wrongfully withheld to the extent that the amount was reasonably related to an amount disputed in good faith.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Are there reasons for which payment may be withheld past the general deadline?

Vermont allows payments to be withheld for any good faith claim against the party requesting payment, including:

  1. Unsatisfactory job progress;
  2. Defective construction;
  3. Disputed work;
  4. Third party claims

Note, however that in the event payments are withheld pursuant to reason 2, above, the deficiency must be described in writing and delivered to the party requesting payment.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Need More Help with Vermont Prompt Payment? We're Here.

Ask an expert for free

Check out our payment experts
Construction attorneys: Courtney Stricklen, Christopher Ng, Andrea Goldman, and Peter Ryan

Vermont Prompt Payment
Recent Questions & Answers

How to file a lien in Vermont

Need to file a Vermont mechanics lien? File your mechanics lien with Levelset, the lien experts quickly and easily. Or you can follow the 3 steps below to file a lien yourself with Levelset’s free information.
File with the Mechanics Lien Experts
Product screenshot suggesting a found material supplier on a project details screen.
We’re the Mechanics Lien experts. With us it’s fast, easy, affordable, and done right!
File Now

Want to Learn More about How Vermont Contractors Pay?
Costco Wholesale Corporation
Rating 5.0
Kaiser Permanente
Rating 5.0
See other Lists of Contractors and How to Best Work With Them

Vermont Prompt Payment Statutes

Getting informed about prompt payment laws is important. An examination of Vermont’s prompt payment laws, the rules and regulations related to payment timing, is important to know your rights and responsibilities as a party on a construction project. Vermont’s specific laws can be found in: Vt. Stat., Title 9 §§ 4001-4009, Title 12 § 2903 , and are reproduced below.

Prompt Payment Statute on Private Projects

Title 9 § 4001: Definitions

As used in this chapter:

(1) “Contractor” means a person or entity which contracts with an owner to perform work, or provide materials or machinery necessary to perform work on real property.

(2) “Work” means to build, alter, repair, or demolish any improvement on, connected with, or on or beneath the surface of any real property, or to excavate, clear, grade, fill, or landscape any real property or to construct driveways, private roadways, highways and bridges, drilled wells, septic, sewage systems, utilities, including trees and shrubbery, or to furnish materials, for any of such purposes, or to perform any labor upon real property. “Work” also includes any design or other professional or skilled services rendered by architects, engineers, land surveyors, landscape architects, and construction managers.

(3) “Owner” means a person or entity having an interest in real property on which work is performed, if the person or entity has agreed to or requested such work. “Owner” includes successors in interest of the owner and agents of the owner acting within their authority. “Owner” shall also include the State of Vermont and instrumentalities and subdivisions of the State of Vermont including municipalities and school districts having an interest in such real property.

(4) “Real property” means real estate, including lands, leaseholds, tenements and hereditaments, and improvements placed thereon.

(5) “Construction contract” means any agreement, whether written or oral, to perform work on any real property located within the State of Vermont.

(6) “Subcontractor” means any person or entity which has contracted to perform work, or provide materials or machinery necessary to perform work for a contractor or another subcontractor in connection with a construction contract.

(7) “Delivery” means receipt by addressee, including first class, registered, or certified mail, hand delivered or transmitted by facsimile machine. Mail, properly addressed, shall be deemed delivered three days from the day it was sent.

(8) “Billing period” means the period agreed to by the parties or, in the absence of an agreement, the calendar month within which work is performed.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4002: Owner's Payment Obligations

(a) The owner shall pay the contractor strictly in accordance with the terms of the construction contract.

(b) In the event that the construction contract does not contain a term governing the terms of payment, the contractor shall be entitled to invoice the owner for progress payments at the end of the billing period. The contractor shall be entitled to submit a final invoice for payment in full upon completion of the agreed-upon work.

(c) Except as otherwise agreed, payment of interim and final invoices shall be due from the owner, 20 days after end of billing period or 20 days after delivery of invoice, whichever is later.

(d) Except as otherwise agreed, if any progress or final payment to a contractor is delayed beyond the due date established in subsection (c) of this section, the owner shall pay the contractor interest, beginning on the 21st day, at an interest rate equal to that established by 12 V.S.A. § 2903(b), on such unpaid balance as may be due.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4003: Contractor's and Subcontractor's Payment Obligations

(a) Performance by a subcontractor in accordance with the provisions of its contract shall entitle it to payment from the party with which it contracts.

(b) Notwithstanding any contrary agreement, a contractor or subcontractor shall disclose to a subcontractor, before a subcontract is entered, the due date for receipt of payments from the owner. Notwithstanding any other provision of this chapter, if a contractor or subcontractor fails to accurately disclose the due date to a subcontractor, the contractor or subcontractor shall be obligated to pay the subcontractor as though the 20-day due dates in subsection 4002(c) of this title were met by the owner.

(c) Notwithstanding any contrary agreement, when a subcontractor has performed in accordance with the provisions of its contract, a contractor shall pay to the subcontractor, and each subcontractor shall in turn pay to its subcontractors, the full or proportional amount received for each such subcontractor’s work and materials based on work completed or service provided under the subcontract, seven days after receipt of each progress or final payment or seven days after receipt of the subcontractor’s invoice, whichever is later.

(d) Notwithstanding any contrary agreement, if any progress or final payment to a subcontractor is delayed beyond the due date established in subsections (b) or (c) of this section, the contractor or subcontractor shall pay its subcontractor interest, beginning on the next day, at an interest rate equal to that established by 12 V.S.A. § 2903(b), on such unpaid balance as may be due.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4004: Errors in Documentation

If an invoice is filled out incorrectly, or incompletely, or if there is any defect or impropriety in an invoice submitted, the receiving owner, contractor, or subcontractor, shall contact the invoicing contractor or subcontractor in writing within ten working days of receiving the invoice. Otherwise, documentary errors shall be deemed waived. If an error on the invoice is corrected by the invoicing contractor or subcontractor, the date on which the corrected invoice is delivered shall be deemed the end of the billing period for the purposes of this chapter.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4005: Retainage

(a) If payments under a construction contract are subject to retainage, any amounts which have been retained during the performance of the contract and which are due to be released to the contractor upon final completion shall be paid within 30 days after final acceptance of the work.

(b) If an owner is not withholding retainage, a contractor may withhold retainage from its subcontractor in accordance with their agreement. The retainage shall be paid within 30 days after final acceptance of the work.

(c) Notwithstanding any contrary agreement, a contractor shall pay to its subcontractors, and each subcontractor shall in turn pay to its subcontractors, within seven days after receipt of the retainage, the full amount due to each such subcontractor.

(d) If an owner, contractor, or subcontractor unreasonably withholds acceptance of the work or fails to pay retainage as required by this section, the owner, contractor or subcontractor shall be subject to the interest, penalty, and attorney’s fees provisions of sections 4002, 4003, and 4007 of this title.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4005a: Fund Held in trust; Commingling; No effect on title to Real Property

a) As used in this section:

(1) “Claim” means any valid claim for materials furnished or services rendered in the construction, repair, remodeling, improvement, or renovation of any building or structure for which the claimant has a lien or the right to claim a lien.

(2) “Express trust” means funds that have been paid by an owner, for or in connection with services, labor, or materials used in an improvement of real property, which are to be held by a contractor or subcontractor, in express trust, for those services, labor, or materials. Any such contractor or subcontractor who accepts money from any owner or contractor shall become the trustee of the express trust that is created pursuant to this section. The amounts received by such contractor or subcontractor under or in connection with each building project shall be a separate trust and the contractor or subcontractor, or any successor or assign or both of such contractor or subcontractor that hold such trust funds, shall be a trustee thereof. These funds are not required to be held in any separate account by a contractor or subcontractor. Such trust shall be effective against and shall have priority over any unsecured interest of a party seeking payment from such contractor or subcontractor for claims other than those that are due and owing by reason of the specific building project for which the trust was created, whether such creditors are foreign attachment or other judicial lien creditors, a trustee in bankruptcy, or similar creditors or representatives or creditors of the contractor or subcontractor.

(b) Funds held in express trust are not required to be held in any separate account by a contractor or subcontractor.

(c) No express trust shall be required for a federal, State, or municipal project.

(d) The amount payable to any contractor or subcontractor under any contract for the construction, repair, remodeling, improvement, or renovation of any building or structure shall, upon receipt by such contractor or subcontractor, be held in express trust by such contractor or subcontractor for the payment of all claims that are due and owing, or to become due and owing, by such contractor or subcontractor by reason of such construction, repair, remodeling, improvement, or renovation.

(e) Any amount required to be held in express trust under this section shall be applied to the payment of the corresponding claims specified in this section.

(f) Nothing herein shall be construed to create a lien on real property. The existence of an express trust under this section shall not prohibit the filing or enforcement of a lien against the affected real property pursuant to chapter 51 of this title by any claimant. A priority lien of a secured lender shall not be subordinate to an express trust.

(g) In the case of an express trust which is not held by a corporation, limited liability partnership, or limited liability company, liability for sums due under this section shall only attach to the principal or head of the company which holds the funds under the express trust.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4006: Prepayment; Advance Payment

This chapter shall in no way be construed to prohibit an owner, contractor, or subcontractor from making advance payments, progress payments or from prepaying if agreements or other circumstances make such payments appropriate. All such payments shall be made promptly and shall be subject to the interest, penalties, and other provisions hereof when payment is later.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4007: Disputes; Penalties; Attorney's Fees

(a) Nothing in this chapter shall prevent an owner, contractor, or subcontractor from withholding payment in whole or in part under a construction contract in an amount equalling the value of any good faith claims against an invoicing contractor or subcontractor, including claims arising from unsatisfactory job progress, defective construction, disputed work, or third-party claims.

(b) If arbitration or litigation is commenced to recover payment due under the terms of this chapter and it is determined that an owner, contractor, or subcontractor has failed to comply with the payment terms of this chapter, the arbitrator or court shall award, in addition to all other damages due and as a penalty, an amount equal to one percent per month of all sums as to which payment has wrongfully been withheld. An amount shall not be deemed to have been wrongfully withheld to the extent it bears a reasonable relation to the value of any claim held in good faith by the owner, contractor or subcontractor against which an invoicing contractor, or subcontractor is seeking to recover payment.

(c) Notwithstanding any contrary agreement, the substantially prevailing party in any proceeding to recover any payment within the scope of this chapter shall be awarded reasonable attorney’s fees in an amount to be determined by the court or arbitrator, together with expenses.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4008: Contracts Involving Federal Aid

Notwithstanding any provision of this chapter, language varying the requirements of this chapter may be included in contracts when such variance is required by any statute, regulation, or grant agreement conditioning the receipt or expenditure of federal aid.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4009: Owner Exclusion

This chapter shall not apply to contracts for the purchase of materials by a natural person performing work on his or her own real property.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 12 § 2903: Duration and Effectiveness

(a) A judgment lien shall be effective for eight years from the issuance of a final judgment on which it is based except that an action to foreclose the judgment lien during the eight-year period shall extend the period until the termination of the foreclosure suit if a copy of the complaint is filed in the land records on or before eight years from the issuance of the final judgment.

(b) A judgment which is renewed or revived pursuant to section 506 of this title shall constitute a lien on real property for eight years from the issuance of the renewed or revived judgment if recorded in accordance with this chapter. The renewed or revived judgment shall relate back to the date on which the original lien was first recorded if a copy of the complaint to renew the judgment was recorded in the land records where the property lies within eight years after the rendition of the judgment, and the renewed or revived judgment is subsequently recorded in accordance with this chapter.

(c) Interest on a judgment lien shall accrue at the rate of 12 percent per annum.

(d) If a judgment lien is not satisfied within 30 days of recording, it may be foreclosed and redeemed as provided in this title and V.R.C.P. 80.1. Unless the court finds that as of the date of foreclosure the amount of the outstanding debt exceeds the value of the real property being foreclosed, section 4531 of this title shall apply to foreclosure of a judgment lien.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Prompt Payment Statute on Public Projects

Title 9 § 4001: Definitions

As used in this chapter:

(1) “Contractor” means a person or entity which contracts with an owner to perform work, or provide materials or machinery necessary to perform work on real property.

(2) “Work” means to build, alter, repair, or demolish any improvement on, connected with, or on or beneath the surface of any real property, or to excavate, clear, grade, fill, or landscape any real property or to construct driveways, private roadways, highways and bridges, drilled wells, septic, sewage systems, utilities, including trees and shrubbery, or to furnish materials, for any of such purposes, or to perform any labor upon real property. “Work” also includes any design or other professional or skilled services rendered by architects, engineers, land surveyors, landscape architects, and construction managers.

(3) “Owner” means a person or entity having an interest in real property on which work is performed, if the person or entity has agreed to or requested such work. “Owner” includes successors in interest of the owner and agents of the owner acting within their authority. “Owner” shall also include the State of Vermont and instrumentalities and subdivisions of the State of Vermont including municipalities and school districts having an interest in such real property.

(4) “Real property” means real estate, including lands, leaseholds, tenements and hereditaments, and improvements placed thereon.

(5) “Construction contract” means any agreement, whether written or oral, to perform work on any real property located within the State of Vermont.

(6) “Subcontractor” means any person or entity which has contracted to perform work, or provide materials or machinery necessary to perform work for a contractor or another subcontractor in connection with a construction contract.

(7) “Delivery” means receipt by addressee, including first class, registered, or certified mail, hand delivered or transmitted by facsimile machine. Mail, properly addressed, shall be deemed delivered three days from the day it was sent.

(8) “Billing period” means the period agreed to by the parties or, in the absence of an agreement, the calendar month within which work is performed.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4002: Owner's Payment Obligations

(a) The owner shall pay the contractor strictly in accordance with the terms of the construction contract.

(b) In the event that the construction contract does not contain a term governing the terms of payment, the contractor shall be entitled to invoice the owner for progress payments at the end of the billing period. The contractor shall be entitled to submit a final invoice for payment in full upon completion of the agreed-upon work.

(c) Except as otherwise agreed, payment of interim and final invoices shall be due from the owner, 20 days after end of billing period or 20 days after delivery of invoice, whichever is later.

(d) Except as otherwise agreed, if any progress or final payment to a contractor is delayed beyond the due date established in subsection (c) of this section, the owner shall pay the contractor interest, beginning on the 21st day, at an interest rate equal to that established by 12 V.S.A. § 2903(b), on such unpaid balance as may be due.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4003: Contractor's and Subcontractor's Payment Obligations

(a) Performance by a subcontractor in accordance with the provisions of its contract shall entitle it to payment from the party with which it contracts.

(b) Notwithstanding any contrary agreement, a contractor or subcontractor shall disclose to a subcontractor, before a subcontract is entered, the due date for receipt of payments from the owner. Notwithstanding any other provision of this chapter, if a contractor or subcontractor fails to accurately disclose the due date to a subcontractor, the contractor or subcontractor shall be obligated to pay the subcontractor as though the 20-day due dates in subsection 4002(c) of this title were met by the owner.

(c) Notwithstanding any contrary agreement, when a subcontractor has performed in accordance with the provisions of its contract, a contractor shall pay to the subcontractor, and each subcontractor shall in turn pay to its subcontractors, the full or proportional amount received for each such subcontractor’s work and materials based on work completed or service provided under the subcontract, seven days after receipt of each progress or final payment or seven days after receipt of the subcontractor’s invoice, whichever is later.

(d) Notwithstanding any contrary agreement, if any progress or final payment to a subcontractor is delayed beyond the due date established in subsections (b) or (c) of this section, the contractor or subcontractor shall pay its subcontractor interest, beginning on the next day, at an interest rate equal to that established by 12 V.S.A. § 2903(b), on such unpaid balance as may be due.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4004: Errors in Documentation

If an invoice is filled out incorrectly, or incompletely, or if there is any defect or impropriety in an invoice submitted, the receiving owner, contractor, or subcontractor, shall contact the invoicing contractor or subcontractor in writing within ten working days of receiving the invoice. Otherwise, documentary errors shall be deemed waived. If an error on the invoice is corrected by the invoicing contractor or subcontractor, the date on which the corrected invoice is delivered shall be deemed the end of the billing period for the purposes of this chapter.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4005: Retainage

(a) If payments under a construction contract are subject to retainage, any amounts which have been retained during the performance of the contract and which are due to be released to the contractor upon final completion shall be paid within 30 days after final acceptance of the work.

(b) If an owner is not withholding retainage, a contractor may withhold retainage from its subcontractor in accordance with their agreement. The retainage shall be paid within 30 days after final acceptance of the work.

(c) Notwithstanding any contrary agreement, a contractor shall pay to its subcontractors, and each subcontractor shall in turn pay to its subcontractors, within seven days after receipt of the retainage, the full amount due to each such subcontractor.

(d) If an owner, contractor, or subcontractor unreasonably withholds acceptance of the work or fails to pay retainage as required by this section, the owner, contractor or subcontractor shall be subject to the interest, penalty, and attorney’s fees provisions of sections 4002, 4003, and 4007 of this title.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4005a: Fund Held in trust; Commingling; No effect on title to Real Property

a) As used in this section:

(1) “Claim” means any valid claim for materials furnished or services rendered in the construction, repair, remodeling, improvement, or renovation of any building or structure for which the claimant has a lien or the right to claim a lien.

(2) “Express trust” means funds that have been paid by an owner, for or in connection with services, labor, or materials used in an improvement of real property, which are to be held by a contractor or subcontractor, in express trust, for those services, labor, or materials. Any such contractor or subcontractor who accepts money from any owner or contractor shall become the trustee of the express trust that is created pursuant to this section. The amounts received by such contractor or subcontractor under or in connection with each building project shall be a separate trust and the contractor or subcontractor, or any successor or assign or both of such contractor or subcontractor that hold such trust funds, shall be a trustee thereof. These funds are not required to be held in any separate account by a contractor or subcontractor. Such trust shall be effective against and shall have priority over any unsecured interest of a party seeking payment from such contractor or subcontractor for claims other than those that are due and owing by reason of the specific building project for which the trust was created, whether such creditors are foreign attachment or other judicial lien creditors, a trustee in bankruptcy, or similar creditors or representatives or creditors of the contractor or subcontractor.

(b) Funds held in express trust are not required to be held in any separate account by a contractor or subcontractor.

(c) No express trust shall be required for a federal, State, or municipal project.

(d) The amount payable to any contractor or subcontractor under any contract for the construction, repair, remodeling, improvement, or renovation of any building or structure shall, upon receipt by such contractor or subcontractor, be held in express trust by such contractor or subcontractor for the payment of all claims that are due and owing, or to become due and owing, by such contractor or subcontractor by reason of such construction, repair, remodeling, improvement, or renovation.

(e) Any amount required to be held in express trust under this section shall be applied to the payment of the corresponding claims specified in this section.

(f) Nothing herein shall be construed to create a lien on real property. The existence of an express trust under this section shall not prohibit the filing or enforcement of a lien against the affected real property pursuant to chapter 51 of this title by any claimant. A priority lien of a secured lender shall not be subordinate to an express trust.

(g) In the case of an express trust which is not held by a corporation, limited liability partnership, or limited liability company, liability for sums due under this section shall only attach to the principal or head of the company which holds the funds under the express trust.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4006: Prepayment; Advance Payment

This chapter shall in no way be construed to prohibit an owner, contractor, or subcontractor from making advance payments, progress payments or from prepaying if agreements or other circumstances make such payments appropriate. All such payments shall be made promptly and shall be subject to the interest, penalties, and other provisions hereof when payment is later.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4007: Disputes; Penalties; Attorney's Fees

(a) Nothing in this chapter shall prevent an owner, contractor, or subcontractor from withholding payment in whole or in part under a construction contract in an amount equalling the value of any good faith claims against an invoicing contractor or subcontractor, including claims arising from unsatisfactory job progress, defective construction, disputed work, or third-party claims.

(b) If arbitration or litigation is commenced to recover payment due under the terms of this chapter and it is determined that an owner, contractor, or subcontractor has failed to comply with the payment terms of this chapter, the arbitrator or court shall award, in addition to all other damages due and as a penalty, an amount equal to one percent per month of all sums as to which payment has wrongfully been withheld. An amount shall not be deemed to have been wrongfully withheld to the extent it bears a reasonable relation to the value of any claim held in good faith by the owner, contractor or subcontractor against which an invoicing contractor, or subcontractor is seeking to recover payment.

(c) Notwithstanding any contrary agreement, the substantially prevailing party in any proceeding to recover any payment within the scope of this chapter shall be awarded reasonable attorney’s fees in an amount to be determined by the court or arbitrator, together with expenses.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4008: Contracts Involving Federal Aid

Notwithstanding any provision of this chapter, language varying the requirements of this chapter may be included in contracts when such variance is required by any statute, regulation, or grant agreement conditioning the receipt or expenditure of federal aid.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 9 § 4009: Owner Exclusion

This chapter shall not apply to contracts for the purchase of materials by a natural person performing work on his or her own real property.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Title 12 § 2903: Duration and Effectiveness

(a) A judgment lien shall be effective for eight years from the issuance of a final judgment on which it is based except that an action to foreclose the judgment lien during the eight-year period shall extend the period until the termination of the foreclosure suit if a copy of the complaint is filed in the land records on or before eight years from the issuance of the final judgment.

(b) A judgment which is renewed or revived pursuant to section 506 of this title shall constitute a lien on real property for eight years from the issuance of the renewed or revived judgment if recorded in accordance with this chapter. The renewed or revived judgment shall relate back to the date on which the original lien was first recorded if a copy of the complaint to renew the judgment was recorded in the land records where the property lies within eight years after the rendition of the judgment, and the renewed or revived judgment is subsequently recorded in accordance with this chapter.

(c) Interest on a judgment lien shall accrue at the rate of 12 percent per annum.

(d) If a judgment lien is not satisfied within 30 days of recording, it may be foreclosed and redeemed as provided in this title and V.R.C.P. 80.1. Unless the court finds that as of the date of foreclosure the amount of the outstanding debt exceeds the value of the real property being foreclosed, section 4531 of this title shall apply to foreclosure of a judgment lien.

Summary
Vermont Prompt Payment Law
Article Name
Vermont Prompt Payment Law
Description
Summary of Vermont Prompt Payment requirements and laws for Vermont construction projects including free forms, FAQs, resources and more.
Author
Publisher Name
Levelset
Publisher Logo

Trusted by Thousands of Vermont Contractors Like You
For Help With Prompt Payment